Last Updated: April 5, 2025
Welcome to All Site Builders. By accessing or using our website at https://allsiteroofingct.com , you agree to comply with and be bound by the following Terms of Service. These terms apply to all visitors, users, and clients who engage with our services.
If you do not agree with any part of these terms, please do not use our website or services.
1. Services Provided
All Site Builders provides residential roofing services, vinyl siding replacement, gutter installation, emergency roof repairs, and other exterior home improvement services in Central and Southern Connecticut. All work is performed by licensed, insured professionals (HIC.0670316).
Quotes and inspections are free and provided for informational purposes only. A formal agreement or contract may be required before work begins.
2. Accuracy of Information
While we strive to provide accurate and up-to-date information on our website, we do not guarantee the completeness, reliability, or suitability of any content, pricing, or service details. Service availability, timelines, and material costs are subject to change without notice.
3. Client Responsibilities
Clients are responsible for providing clear access to the work site, accurate property information, and timely communication. Any delays caused by the client may affect project timelines.
4. Estimates and Payments
All estimates are non-binding and based on the information available at the time. Final pricing will be confirmed in writing before work commences. Payment terms, including deposits and final balances, will be outlined in the service agreement.
5. Limitation of Liability
All Site Builders shall not be held liable for indirect, incidental, or consequential damages arising from the use of our services or website. We are not responsible for pre-existing conditions not disclosed by the client, including hidden structural damage or water intrusion.
Our liability for any claim related to our services is limited to the amount paid by the client for the specific project in question.
6. Cancellations and Delays
Clients may cancel a project before work begins, subject to any non-refundable deposit terms outlined in the agreement. Weather, material delays, or unforeseen site conditions may impact project schedules. We will communicate any delays promptly.
7. Intellectual Property
All content on this website, including text, images, logos, and design, is the property of All Site Builders and protected by copyright laws. Unauthorized use, reproduction, or distribution is prohibited.
8. Governing Law
These Terms of Service are governed by the laws of the State of Connecticut. Any disputes arising from our services or this agreement shall be resolved in the courts of the state of Connecticut.
9. Changes to These Terms
We may update these Terms of Service from time to time. Any changes will be posted on this page with a new «Last Updated» date. We encourage you to review this page periodically.
10. Contact Us
If you have any questions about these Terms of Service, please contact us:
With Expert Roofing & Exterior Services from All Site Builders
Roofing contractor also specializing in sideng, windows, desks and patios.
Licensed, insured, Owens Corning Preferred & GAF Certified Plus. Quality roofing and exterior services across CT since 2005.
